Concurrent Delays: A Commentary for Planning and Cost Managers
Iain Wishart's 1996 paper, "Concurrent Delays," presented to the Society of Construction Law (SCL) in London, tackles a prevalent and often misunderstood challenge in construction projects: concurrent delays. This commentary aims to provide a comprehensive overview of the paper's key insights, focusing on their relevance to planning and cost managers.
The Problem of Concurrent Delays
Wishart highlights the pervasive nature of concurrent delays, where both the contractor and the owner contribute to delays in a project. This situation is more common than not, yet often disregarded in analysis, leading to complications in extending time, calculating losses, and managing expenses. The core issue is often not about time, but about money.
He emphasizes the importance of understanding the underlying financial implications. Contractors tend to seek more money due to delay, and the potential for substantial costs related to extensions, disruptions, or accelerations further complicates the situation. This economic pressure fuels the prevalence of claims, making it vital for planning and cost managers to navigate this territory with clarity and precision.
The Need for Clarity and Practicality
The paper highlights a critical lack of clarity and consistent approach to dealing with concurrent delays in existing contracts. Wishart critiques existing legal approaches and theories like the Devlin approach, the dominant cause approach, and the burden of proof approach, concluding that they often result in an "all-or-nothing" outcome, leaving one party in a better position than they should be while potentially disadvantaging the other. This lack of fairness and ambiguity creates a significant challenge for planning and cost managers.
The Importance of Contractual Clarity
Wishart argues that relying on contractual provisions for clarity is essential. He emphasizes the importance of clear definitions, specific requirements for notification, and detailed processes for identifying, documenting, and evaluating the impact of concurrent delays. This contractual clarity is fundamental for minimizing potential disputes and facilitating a fair and transparent approach to handling concurrent delay situations.
The "Made Whole" Principle and Practical Application
While recognizing the complexity of the issue, Wishart advocates for adopting the "made whole" principle in concurrent delay situations. This principle calls for placing the contractor back into the same position they would have been in had the delay not occurred. He emphasizes that this approach, while seemingly straightforward, requires meticulous planning and analysis. Wishart provides a real-world example involving a house construction project to illustrate how to apply the "made whole" principle in practice. This real-world example demonstrates the complexity of identifying and allocating responsibility for different delays and underscores the importance of accurate time analysis, careful assessment of the impact of each delay, and meticulous documentation to support any claims or requests for extensions.
Recommended by LinkedIn
The US Approach and Its Potential Relevance
The paper explores the US approach to concurrent delays, where the "no-win" rule often applies. Under this rule, neither party can recover damages when both contribute to the delay, effectively forcing them to accept the consequences. Wishart acknowledges the potential for fairness in this approach, as it prevents one party from unfairly benefiting at the expense of the other. He suggests that adopting a similar approach in the UK could potentially bring greater fairness and clarity to the resolution of concurrent delay situations.
Practical Guidance for Planning and Cost Managers
Here are some practical takeaways for planning and cost managers based on the paper:
Challenges and Future Considerations
While Wishart's paper provides valuable insights, several challenges and areas for further exploration remain:
Conclusion: A Call to Action for the Construction Industry
Wishart's paper serves as a timely reminder that the issue of concurrent delays is complex and needs a more systematic, transparent, and fair approach. By adopting a proactive approach to planning, carefully reviewing contracts, and embracing open communication, planning and cost managers can effectively navigate this complex territory, minimizing disputes and ensuring a more equitable and predictable construction environment.
FCIARB, FIITARB, FIE, FIV, LLM( Pro), PGD NALSAR , Diploma in Arbitration Practice, MA Mediation, A construction contract and ADR expert
1moVery Interesting write up. So useful. Would be grateful to receive more information on the topic, sir